Effective Date: September 10, 2024
Welcome to Astute Inhabit. By accessing or using our website and services, you agree to be bound by the following Terms of Service. Please read them carefully.
1. Acceptance of Terms
By using our e-commerce platform or engaging in our construction services, you agree to comply with and be legally bound by these terms. If you do not agree to these terms, please refrain from using our services.
2. Services
Astute Inhabit offers a range of e-commerce products, including construction materials and related goods, as well as construction services. Our services include project management, consultation, and execution of construction projects tailored to client specifications. All products and services are subject to availability and project scope.
3. User Responsibilities
As a user of our e-commerce site or a client of our construction services, you agree to provide accurate and complete information during the order or consultation process. You also agree to use our website and services for lawful purposes only and comply with all applicable regulations, including zoning and construction laws in Maryland.
4. Payment Terms
All payments for products and services must be made in accordance with the payment terms agreed upon at checkout (for e-commerce) or during the contract negotiation phase (for construction services). For construction projects, payment schedules may be outlined in contracts, and failure to adhere to these may result in delays or additional charges.
5. Shipping and Delivery
For e-commerce products, we strive to ship and deliver items within the estimated time frame. Delivery dates are estimates and may vary based on external factors. We are not responsible for delays caused by third-party shipping companies.
6. Returns and Refunds
E-commerce products may be returned or refunded in accordance with our [Insert Return Policy]. For construction services, refunds are typically not available once a project has commenced unless otherwise specified in the contract.
7. Intellectual Property
All content, products, designs, and intellectual property on our website and related to Astute Inhabit are the property of the company and cannot be used or distributed without explicit written permission.
8. Warranty and Disclaimer
For e-commerce products, we provide warranties in accordance with the manufacturer’s guidelines, if applicable. For construction services, warranties on workmanship may vary based on the project scope and will be detailed in the contract. We make no other warranties beyond what is explicitly stated.
9. Limitation of Liability
Astute Inhabit is not liable for any indirect, incidental, or consequential damages arising from the use of our website, products, or services. For construction projects, we are not responsible for delays or damages caused by unforeseen events, including but not limited to weather, supply chain disruptions, or regulatory issues.
10. Modifications to Terms
We reserve the right to modify these Terms of Service at any time. Any changes will be posted on this page, and your continued use of the site or services following the posting of changes constitutes your acceptance of such changes.
11. Governing Law
These terms are governed by and construed in accordance with the laws of the State of Maryland. Any disputes arising from these terms or the use of our services will be resolved in the courts of Maryland.
12. Contact Information
For any questions or concerns regarding these terms, please contact us at [Insert Contact Information].